Welcome to Yardie. By accessing or using our services, website, or any related platforms (collectively referred to as “Services”), you agree to comply with and be bound by the following Terms of Service (“Terms”). Please read these terms carefully before engaging with Yardie. If you do not agree with any part of these terms, you must not use our Services.

1. Acceptance of Terms
‍By using our Services, you acknowledge that you have read, understood, and agree to be bound by these Terms, as well as any other policies referenced herein, including our Privacy Policy. These Terms apply to all users of our Services, including but not limited to clients, contractors, and visitors to our website.

2. Services Provided
‍Yardie specializes in exterior design, landscaping, and related services. These services may include, but are not limited to:
Landscape design and consultation
Installation of outdoor features (e.g., patios, walkways, gardens)
Lawn care and maintenance
Irrigation system design and installation
Specific terms, pricing, and deliverables for individual services will be outlined in separate agreements or project quotes provided to you before work begins.

3. User Responsibilities
‍As a user of our Services, you agree to:
Provide accurate and complete information when requesting quotes or services.
Comply with all applicable laws, rules, and regulations.
Promptly communicate any changes or issues related to the scope of work.
Make payments in a timely manner in accordance with the terms outlined in any agreements.

You also agree not to misuse our Services in any way, including but not limited to:
Engaging in any unlawful, fraudulent, or harmful activity.
Interfering with the proper functioning of our website or Services.
Attempting to access unauthorized areas of our systems or data.

4. Quotes and Contracts
‍All project quotes provided by Yardie are estimates based on the information provided at the time of consultation. Final pricing may vary depending on factors such as material costs, project modifications, or unforeseen challenges during installation. Any changes to the original scope of work will be communicated, and approval will be required before proceeding.

Separate contracts or agreements may govern specific services, and those documents will take precedence over these Terms if there is a conflict.

5. Payments and Billing
‍You agree to pay the fees outlined in the project quote or contract, including applicable taxes. Payments may be required in installments based on project milestones or upfront deposits as specified in individual contracts. Failure to make timely payments may result in project delays, additional fees, or termination of services.

All payments made to Yardie are non-refundable unless stated otherwise in a specific contract or agreement.

6. Cancellations and Refunds
‍You may cancel services at any time by providing written notice to Yardie. If you cancel after work has commenced, you may be liable for any costs incurred up to the point of cancellation. This includes but is not limited to materials ordered, labor costs, or cancellation fees.Refunds, if applicable, will be handled in accordance with the terms outlined in individual contracts or project agreements.

7. Intellectual Property
‍All content, designs, plans, and materials created by Yardie as part of our Services remain the intellectual property of Yardie unless otherwise agreed upon in writing. You may not reproduce, distribute, or otherwise use Yardie's designs or materials for any purpose without prior written consent.

8. Warranties and Disclaimers
‍Yardie strives to deliver high-quality services but makes no specific guarantees or warranties regarding the results or outcomes of our projects. The services are provided on an "as-is" basis, and we disclaim any implied warranties of merchantability, fitness for a particular purpose, or non-infringement.
We are not responsible for issues that arise due to natural events (e.g., weather-related damage), pre-existing conditions on the property, or other factors beyond our control.

9. Limitation of Liability
‍To the maximum extent permitted by law, Yardie and its affiliates, employees, contractors, or partners shall not be liable for any indirect, incidental, special, consequential, or punitive damages arising out of or related to your use of our Services, even if advised of the possibility of such damages.
Our total liability for any claim arising out of these Terms or the use of our Services shall be limited to the amount paid by you for the specific service that gave rise to the claim.

10. Termination
‍Yardie reserves the right to terminate or suspend your access to our Services at any time, with or without cause or notice. Upon termination, all provisions of these Terms that by their nature should survive termination shall remain in effect, including but not limited to intellectual property, payment obligations, and limitations of liability.

11. Changes to Terms
‍We reserve the right to modify these Terms at any time. Any changes will be posted on our website with an updated effective date. Continued use of our Services after such changes constitutes your acceptance of the new Terms.

12. Governing Law
‍These Terms shall be governed and construed in accordance with the laws of North Carolina, without regard to its conflict of law provisions. Any disputes arising under these Terms will be resolved in the courts located in North Carolina.

13. Contact Us
‍If you have any questions or concerns regarding these Terms of Service, please contact us at: 252-714-6959